43--PUMP,CENTRIFUGAL - AND SIMILAR REPLACEMENT PARTS, IN REPAIR/MODIFICATION OF

NSN 7H-4320-013186355, TDP VER 010, QTY 100 EA, DELIVERY FOB ORIGIN. IMPORTANT NOTE: This RFQ is for repair. Any asset for which the contractor does not meet the required RTAT will incur a price reduction per unit/per month the contractor is late - any delay determined to be excusable (e.g. Government Delay) will not result in a price reduction. If a price reduction is required due to unexcusable contractor delay, the Contracting Officer will implement the aforementioned price reduction via a "reconciliation modification" at the end of the contract performance. Price reductions made pursuant to this section shall not limit .... Read More

ITEM UNIQUE IDENTIFICATION AND VALUATION (JAN 2023)|19|||||||||||||||||||| INSPECTION OF SUPPLIES--FIXED-PRICE (AUG 1996)|2||| TIME OF DELIVERY (JUNE 1997)|20|0001AA|100|90|0002AA|90|124||||||||||||||| STOP-WORK ORDER (AUG 1989)|1|| WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2023)|16|TBD|TBD|TBD|N00104|TBD|TBD|see schedule page|TBD|TBD|TBD|TBD|||||| NAVY USE OF ABILITYONE SUPPORT CONTRACTOR - RELEASE OF OFFEROR INFORMATION (3-18))|1|WSS| VALUE ENGINEERING (JUN 2020)|3|||| EQUAL OPPORTUNITY (SEP 2016)|2||| SMALL BUSINESS SUBCONTRACTING PLAN (DOD CONTRACTS)- BASIC (DEC 2019)|2||| INTEGRITY OF UNIT PRICES (NOV 2021)|1|| EQUAL OPPORTUNITY FOR VETERANS (JUN 2020)|4||||| WARRANTY OF DATA--BASIC (MAR 2014)|2||| SMALL BUSINESS SUBCONTRACTING PLAN (SEP 2023)|4||||| SAFEGUARDING SENSITIVE CONVENTIONAL ARMS, AMMUNITION, AND EXPLOSIVES (NOV 2023))|9|||||||||| EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (JUN 2020)|2||| TRANSPORTATION .... Read More

NSN 7H-4320-013186355, TDP VER 010, QTY 100 EA, DELIVERY FOB ORIGIN. IMPORTANT NOTE: This RFQ is for repair. Any asset for which the contractor does not meet the required RTAT will incur a price reduction per unit/per month the contractor is late - any delay determined to be excusable (e.g. Government Delay) will not result in a price reduction. If a price reduction is required due to unexcusable contractor delay, the Contracting Officer will implement the aforementioned price reduction via a "reconciliation modification" at the end of the contract performance. Price reductions made pursuant to this section shall not limit .... Read More